MOTIVITY TECHNOLOGIES LLC
GENERAL TERMS AND CONDITIONS OF SALE
PARTIES. “Seller” shall mean Motivity Technologies, LLC (and its subsidiaries and affiliates). “Buyer” shall mean the entity or person submitting the purchase order to Motivity Technologies, LLC.
ACCEPTANCE. Buyer acknowledges and agrees that these General Terms and Conditions are incorporated in, and are a part of, this Agreement and each purchase order, release, requisition, scope of work, shipping instruction, specification and other document, whether expressed verbally, in written form or electronic commerce, relating to the products and/or services to be provided by Seller pursuant to this Agreement (such documents are collectively referred to as the “Agreement”), and that Seller’s acceptance of Buyer’s offer to purchase is made conditional upon the incorporation of these General Terms and Conditions into the Agreement. If Buyer accepts the products and/or services which are the subject of the Agreement, Buyer shall be deemed to have accepted the Agreement including these General Terms and Conditions in their entirety without modification. Any additions to, changes in, modifications or revisions of the Agreement (including these General Terms and Conditions) shall require the written consent of an authorized representative of Seller. All stenographic and clerical errors are subject to correction by Seller.
QUOTATION EXPIRATION. Written quotations are valid for a period of thirty (30) days except for pipe and wire unless otherwise noted by Seller. Quotations for pipe and wire are valid for 24 hours unless otherwise noted by Seller. Seller shall have the right to withdraw any quote which has not been accepted by Buyer.
PRICING. Prices for products and other related information shown in any Seller or manufacturer product publication including, but not limited to catalogs, brochures and websites are subject to change without notice. Prices do not include related freight charges, use tax, sales tax, excise tax, value-added tax, or similar taxes, duty, customs, inspection or testing fees, or charge of any nature whatsoever imposed by any governmental authority unless otherwise noted by Seller. Service rates and fees will be identified in Seller’s quotation. Any actual, out-of-pocket expenses, including for hardware and/or software, reasonably incurred by Seller in performing the project will be invoiced to Buyer, with Buyer’s advance approval for such expenses. Any expenses for travel, including but not limited to mileage, airfare, lodging and per diem expenses for meals will be invoiced at Seller’s then-current rates, which rates will be provided to Buyer for advance approval. All time Seller personnel spends performing services is billable, including time spent both on site and off site.
PRODUCT DELIVERY. Shipment of products will be made F.O.B. (a) Seller’s facility, (b) Seller’s supplier’s facility when products are shipped directly from the manufacturer or (c) as otherwise indicated per Seller’s quotation or order acknowledgment (Ex Works per INCOTERMS 2000 for international shipments). Seller will use commercially reasonable efforts to ensure on time delivery. In no event shall Buyer be entitled to liquidated damages as a remedy for any delay in delivery by Seller. Title and risk of loss pass upon delivery to the delivery point per applicable shipping term. Buyer shall pay all insurance costs associated with delivery. Delay in shipment shall not relieve Buyer of its obligation to accept remaining shipments.
PROJECT DOCUMENTATION. Unless expressly identified in a scope of work, Seller provides no documentation, system reference material or any similar material. Any project documentation desired by Buyer shall be identified in a scope of work. All upgrades, change orders, maintenance, support and similar items are not included in a scope of work unless expressly identified and accepted by Seller.
WORK PRODUCT. All documentation, work product and reports generated in conjunction with the statement of work are owned by Seller. If expressly included in the statement of work, and provided Seller receives full payment under the scope of work, Seller will grant to Buyer a non-exclusive, non-transferable license to use the documentation, work product and reports as set forth in the statement of work, with no rights to sublicense, disclose, disassemble, decompile, reverse engineer, or otherwise modify such items.
LICENSED SOFTWARE AND FIRMWARE. Use of products or services comprised of software or firmware provided by third-parties may be subject to Buyer’s acceptance of additional terms and conditions set forth in separate third-party license agreements. Such agreements will control to the extent necessary to resolve any conflict with these terms and conditions or the third-party agreement. With respect to software code provided by Seller that is not licensed under separate terms, provided Seller receives full payment under the scope of work, Seller grants Buyer a non-exclusive, non-transferable license to use Seller’s provided software code as set forth in the statement of work, with no rights to sublicense, disclose, disassemble, decompile, reverse engineer, or otherwise modify the software. Ownership of Seller’s or a third-party’s software code remains with Seller or the third-party, respectively.
OWNERSHIP OF PRE-EXISTING IP. Each party shall continue to own all right, title and interest in all intellectual property (including trademarks, patents, copyrights, confidential information) it owned prior to this engagement.
TAXES. Any use tax, sales tax, excise tax, duty, custom, value-added tax, inspection or testing fee, or any other tax, fee or charge of any nature whatsoever imposed by any governmental authority, on or measured by the transaction between Seller and Buyer shall be paid by Buyer in addition to price quoted or invoiced. In the event Seller is required to pay any such tax, fee or charge, Buyer shall reimburse Seller therefor or, in lieu of such payment, Buyer shall provide Seller at the time the order is submitted an exemption certificate or other document acceptable to the authority imposing the tax, fee or charge.
PAYMENT. Payment shall be net 30 days from the date of Seller’s invoice without discount for early payment, unless otherwise noted by Seller. Late payments are subject to a service charge equal to 1 1/2 % per month (18% per annum) or the maximum amount permitted under law, if less, until paid. Buyer shall indemnify Seller for all costs of collection of past due amounts including attorney’s fees and court costs. Seller reserves the right at any time to suspend credit, change credit terms or terminate the Agreement or any purchase order, when, in Seller’s sole opinion, Buyer’s financial conditions so warrants. Buyer shall have no right to offset any amounts due or to become due to Seller against any claims, charges, expenses, fees or other payments of any kind whatsoever under any circumstances, including, but not limited to, any liability which may arise due to any breach or alleged breach of the Agreement or any provision thereof. All NSF checks returned to Seller will be subject to a $30 NSF fee. Seller may assign and/or sell any receivables or indebtedness owed by Buyer without notice. If Buyer fails to pay invoiced amounts when due, Seller may then at any time, without waiving any claims it may have and without incurring any liability to Buyer, suspend the work in process until it receives full payment of all outstanding amounts due. Buyer shall be responsible for any reasonable costs incurred by Seller with respect to demobilization and remobilization.
CREDIT CARDS: Credit Cards will be accepted at the time of order from the purchaser. Credit cards are NOT eligible for any payment discounts or special terms. A customer who chooses to pay for an order more than ten (10) days after invoicing is subject to the credit card fee of 2.5% of the total purchase price.
CHANGES; SUSPENSION. Buyer may request changes to the Agreement. Seller shall promptly advise Buyer in writing of the reasonable effect on price and delivery date. Seller shall not be required to institute any Buyer-dictated change until the parties have agreed to an equitable adjustment to the price and/or delivery date. Buyer may, by written notice, request Seller to temporarily suspend performance or delivery hereunder; provided that Seller is reimbursed for additional costs incurred as a result thereof, including but not limited to storage, insurance, preservation, and other reasonable costs attributable to such suspension. Payment of the Agreement price shall become due when Buyer is notified that the products are ready for shipment and Buyer shall be responsible for all price increases instituted by Seller during the period of suspension. Seller shall be granted a reasonable extension of the delivery date to take account of the suspended performance. In the event that the duration of such suspension exceeds ninety (90) days, Seller may, at its option, declare Buyer to be in breach of the Agreement and shall have the right to assert any available remedy under the Agreement or otherwise available at law or in equity. Purchase orders for special, custom or non-stock items or wire cuts may not be cancelable and subject to 100% cancellation charges.
PROJECT SCHEDULING. Seller will perform its work for Buyer at Buyer’s location, Seller’s location, or elsewhere, as determined by Seller to be commercially appropriate. Seller will consult with Buyer in establishing the schedule of the project and the location of services to reasonably accommodate the work schedule of Buyer. If services will be performed at Buyer’s location, Buyer shall provide a safe and accessible work environment. Buyer acknowledges that scheduling changes may be costly and cause unnecessary delays in project completion. Seller will work to reasonably accommodate any schedule changes requested by Buyer, however, any rescheduling or project cancellation may be subject to a rescheduling/cancellation fee of 50% of the scheduled service, plus any prepaid, non-refundable expenses. Buyer acknowledges that cancellations and rescheduling will cause Seller to incur economic damages and losses that are difficult to ascertain, and that the rescheduling/cancellation fees represent fair, reasonable and appropriate estimates of Seller’s damages and losses.
NETWORK CONNECTION. Buyer acknowledges that connecting a network analysis device and related tools used can trigger monitoring systems to identify a foreign device and send alarms or alerts, or otherwise interrupt or compromise network activity or access. Buyer will provide a secure environment and adequate back-up to ensure its systems can be accessed for the purpose of the scope of work, and adequately restored after Seller is granted access. Buyer represents and warrants that its system is capable of facilitating network analysis device and related tools. Buyer assumes the risk of its requested scope of work, and Buyer holds Seller harmless from any adverse network reaction that may occur as a result of network access granted to Seller. Buyer’s compliance with this provision is a material condition to Seller accepting the scope of work.
INSPECTION AND ACCEPTANCE. Buyer shall have five (5) business days from the date of delivery to inspect products for defects and nonconformance and notify Seller, in writing, of any defects, nonconformance or rejection of such products (other than defects or nonconformities due to damage, shortage or errors in shipping which shall be reported as set forth below). Claims for shipping errors or shortages must be made in writing to Seller no more than three (3) business days after receipt of shipment. After such period, Buyer shall be deemed to have irrevocably accepted the products, if not previously accepted. After such acceptance, Buyer shall have no right to reject the products for any reason or revoke acceptance. Claims for damage due to shipping must be made by Buyer to the freight carrier.
RETURN OF PRODUCTS. All returns will be pursuant to Seller’s instructions. Buyer must contact Seller for a Return Material Authorization (RMA) prior to returning any product. All returns must reference the RMA number along with the original invoice number and the reason for return. Non-warranty returns of normal stock products that are unused and are in resalable condition will be subject to Seller’s return policies in effect at the time, including applicable restocking and transportation charges and other conditions of return.
REMEDIES UPON TERMINATION. Upon termination, Buyer shall pay to Seller the following amounts without duplication: (i) the Agreement price for all finished work and completed services which conform to the requirements of the Agreement and not previously paid for; (ii) for products manufactured by others, Buyer shall pay all applicable restocking or cancellation charges including reimbursement for direct costs assessed by the manufacturer (special orders may result in payment of 100% of the Agreement price), (iii) for products manufactured by Seller, Buyer shall pay for reasonable costs including cost of work-in-progress and raw materials purchased by Seller based on Buyer’s purchase order and up to 100% of the Agreement price for special order products.
(a) The warranty obligations of Seller for products, parts, or services manufactured or provided by others and merely sold by Seller shall in all respects conform and be limited to the warranty extended by the manufacturer or service provider, if transferable. Buyer agrees that if products sold hereunder are resold by Buyer, Buyer will include in the agreement for resale provisions which limit recoveries in accordance with these General Terms and Conditions. In case of Buyer’s failure to include in any such agreement for resale the terms providing for such limitations, Buyer shall indemnify and hold Seller harmless against any liability, loss, cost, damage, or expense (including reasonable attorney’s fees) arising out of or resulting from such failure.
(b) Seller warrants that any products or part thereof manufactured or designed by Seller will be free from defects in material or workmanship for a period of one year from the date of installation if installed by Seller or one year from the date of delivery if not installed by Seller. Remedies under the foregoing warranty will be limited, at Seller’s option, to the replacement, repair or modification of, or issuance of a credit for the purchase price of the products. All product shipping expenses and labor, travel, and per deim expenses for repair personnel travel, lodging and premium labor expenses shall be paid by Buyer. This warranty is of no effect if such products claimed to be defective or any part or component thereof shall have been improperly repaired, altered, installed or operated or subjected to misuse, negligence or accident.
(c) Seller warrants to Buyer that it shall (i) perform the services using personnel of required skill, experience, and qualifications and in a professional and workmanlike manner in accordance with generally recognized industry standards for similar services; and (ii) devote adequate resources to meet its obligations under this Agreement. Seller warrants that for a period of 30 days following completion of a service project, all services provided will conform to the applicable scope of work. Seller will promptly re-perform any deficient services or perform a work-around at no additional cost to Buyer, and such re-work will be subject to a new 30 day warranty. Except where Seller has been specifically engaged to produce a work product or solution to meet express requirements of Buyer, Seller does not represent, warranty or covenant that any work product will meet the customer’s requirements, operate in the environment selected by Buyer, or be compatible with Buyer’s intended application. If Seller is unable to correct a defect, Seller will refund the price of the services.
(d) Any warranty claim must be addressed to Seller in writing setting forth sufficient detail to permit identification of the defect and be made within the warranty period set forth above. All claimed defects must be reproducible. No employee or agent of Seller is authorized to make any warranty other than that which is specifically set forth herein. THE FOREGOING OBLIGATIONS ARE IN LIEU OF ALL OTHER OBLIGATIONS AND LIABILITIES INCLUDING ALL WARRANTIES OF FITNESS OR OF MERCHANTABILITY OR OTHERWISE, EXPRESS OR IMPLIED IN FACT OR BY LAW, and state Seller’s entire and exclusive liability and Buyer ‘s exclusive remedy for any claims in connection with the sale of services, products, their design, suitability for use or operations.
(e) Seller makes no warranty regarding third-party software used by Buyer, or its effect on the performance of the software to be developed by Seller for the project.
USE AND SAFETY OF PRODUCTS. SELLER DOES NOT GUARANTEE THAT ANY PRODUCTS PURCHASED HEREUNDER MEET BUYER’S SPECIFICATIONS OR INTENDED USE. FAILURE TO CONSULT THE NATIONAL ELECTRIC CODE AND ANY PERTINENT LOCAL CODES FOR APPROVED INSTALLATION, USE, STORAGE AND REPAIR PROCEDURES AND PRECAUTIONS MAY RESULT IN PROPERTY DAMAGE, INJURY OR DEATH.
RELATIONSHIP OF THE PARTIES. The relationship between the parties is that of independent contractors. Nothing contained in this Agreement shall be construed as creating any agency, partnership, joint venture or other form of joint enterprise, employment or fiduciary relationship between the parties, and neither party shall have authority to contract for or bind the other party in any manner whatsoever. Seller shall be an invited guest at the facility provided by Buyer and Seller shall not be liable to Buyer or to any third-party for Buyer’s acts or omissions.
NONSOLICITATION. Buyer acknowledges that Seller has invested considerable time and expense in developing its personnel and making them available to Buyer to perform the services. Buyer would derive considerable value, and Seller would be deprived of its valuable personnel, if Buyer were to directly hire Seller’s personnel after Seller introduces its personnel to Buyer. Therefore, from the date of this Agreement until twelve (12) months after the expiration or termination of the parties’ business relation, Buyer agrees that it will not solicit for employment, hire or contract with any employee of Seller without the Seller’s prior written consent. If Buyer violates this provision, Buyer agrees to pay Seller an amount equal to 30% of the recruited employee’s first year aggregate compensation with Buyer, as a fee for the additional benefit Seller provided to Buyer.
CONFIDENTIALITY. Buyer acknowledges that Seller’s proposal and all other technical, business and commercial information relating to Seller that is provided to Buyer, whether orally or in writing, constitute confidential and/or proprietary information of Seller (“Confidential Information”). Buyer shall hold the Confidential Information in strict confidence and shall use at least the same degree of care in protecting the confidentiality of the Confidential Information that Buyer uses to protect its own confidential information, but in no event less than reasonable case. Buyer shall not disclose to any third-party or otherwise permit any third-party access to the Confidential Information without the express written consent of Seller. Buyer shall not use the Confidential Information except for the purpose of fulfilling the parties’ Agreement.
INDEMNIFICATION. Buyer represents and warrants that (i) any specifications and information delivered to Seller hereunder do not violate, infringe or constitute a misappropriation of any intellectual property rights of any third party and that Buyer is not aware of any facts upon which such infringement could be based; and (ii) Buyer is in possession of all valid licenses for all third-party software (not provided by Seller) used for the project. Buyer agrees to defend and indemnify Seller, its employees, officers, directors, successors and assigns against any and all claims for damages, claims, suits, penalties, actions, costs and expenses, including reasonable attorneys’ fees (“Losses”) related to or arising out of (a) the breach of the foregoing warranty; (b) the manufacture or sale of all or any part of the products which are manufactured in accordance with the specifications furnished by Buyer; or (c) Buyer’s negligence or willful misconduct; provided that the foregoing indemnification shall not apply to Losses arising solely out of Seller’s willful misconduct or gross negligence. Seller agrees to defend and indemnify Buyer, its employees, officers, directors, successors and assigns against any and all Losses to the extent arising only out of (i) the negligence or willful misconduct of Seller or (ii) as it relates to only products manufactured by Seller, infringement of any patent, copyright, trademark and other intellectual property right of any third party (except for infringement that results from Seller’s compliance with Buyer’s specifications or design, or from Buyer’s combination of Seller’s products with other products or services). NOTWITHSTANDING THE FOREGOING, SELLER PROVIDES NO INDEMNITIES (INTELLECTUAL PROPERTY OR OTHERWISE) RELATIVE TO ANY THIRD-PARTY PRODUCTS OR SERVICES RESOLD BY SELLER.
DISCLAIMER AND LIMITATION OF LIABILITY. TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW, SELLER WILL NOT BE LIABLE FOR ANY FORM OF INCIDENTAL, INDIRECT, SPECIAL, PUNITIVE OR CONSEQUENTIAL DAMAGES OF ANY KIND, INCLUDING BUT NOT LIMITED TO CLAIMS FOR BUSINESS INTERRUPTION OR LOSS OF PROFIT, REVENUE, MATERIALS, ANTICIPATED SAVINGS, DATA, CONTRACT, GOODWILL OR THE LIKE (WHETHER DIRECT OR INDIRECT IN NATURE). SELLER’S MAXIMUM CUMULATIVE LIABILITY RELATIVE TO ALL OTHER CLAIMS AND LIABILITIES, WHETHER OR NOT INSURED, INCLUDING OBLIGATIONS UNDER ANY INDEMNITY, WILL NOT EXCEED THE COST OF THE PRODUCT(S) OR SERVICES GIVING RISE TO THE CLAIM OR LIABILITY. ANY ACTION AGAINST SELLER MUST BE BROUGHT WITHIN TWELVE (12) MONTHS AFTER THE CAUSE OF ACTION ACCRUES. THESE DISCLAIMERS AND LIMITATIONS OF LIABILITY WILL APPLY REGARDLESS OF ANY OTHER CONTRARY PROVISION HEREOF AND REGARDLESS OF THE FORM OF ACTION, WHETHER IN CONTRACT, TORT (INCLUDING NEGLIGENCE AND STRICT LIABILITY) OR OTHERWISE, AND FURTHER WILL EXTEND TO THE BENEFIT OF SELLER’S EMPLOYEES, REPRESENTATIVES AND SUPPLIERS AS THIRD-PARTY BENEFICIARIES. EACH PROVISION HEREOF WHICH PROVIDES FOR A LIMITATION OF LIABILITY, DISCLAIMER OF WARRANTY OR CONDITION OR EXCLUSION OF DAMAGES IS SEVERABLE AND INDEPENDENT OF ANY OTHER PROVISION AND IS TO BE ENFORCED AS SUCH.
SELLER DISCLAIMS ALL LIABILITY RELATIVE TO GRATUITOUS INFORMATION, ANALYSIS AND ASSISTANCE PROVIDED BY, BUT NOT CONTRACTUALLY REQUIRED OF SELLER. ANY SUCH GRATUITOUS INFORMATION, ANALYSIS AND ASSISTANCE IS PROVIDED AS-IS, WHERE-IS.
FORCE MAJEURE. Seller shall not be liable for any loss or damage as a result of any delay in shipment, delivery or installation due to any cause beyond Seller’s reasonable control, including without limitation, flood, hurricane, or other act of God, embargo or other governmental act or authority, regulation or request, fire, theft, accident, strike, slowdown, labor dispute, war, riot delay in transportation, inability to obtain necessary labor, materials or manufacturing facilities, whether at Seller’s operations or at the operations of a supplier or subcontractor to Seller. In the event of any such delay, the date of performance shall be extended for a period equal to the time lost by reason of delay, plus a reasonable time for resuming performance.
EXPORT CONTROL. Products and associated materials supplied by Seller may be subject to various export laws and regulations. It is the responsibility of the exporter to comply with all such laws and regulations. Notwithstanding any other provision to the contrary, in the event that U.S. or local law requires export authorization for the export or re-export of any products or associated technology, no delivery can be made until such export authorization is obtained, regardless of any otherwise promised delivery date. In the event that any required export authorization is denied, Seller and Seller’s supplier will be relieved of any further obligation relative to the sale and delivery of the products subject to such denial without liability of any kind relative to Buyer or any other party. Seller will not comply with boycott related requests except to the extent permitted by U.S. law and then only at Seller’s discretion.
MISCELLANEOUS. Any failure of Seller to insist upon strict performance of any term of this Agreement shall not be construed as a waiver of its right to strict performance thereafter. The Agreement shall be governed by the laws of the State of Michigan, USA, without regard to its conflicts of laws principles. The parties agree that the 1980 UN Convention on Contracts for the International Sale of Products will not apply. Seller and Buyer hereby agree that any legal proceeding with respect to the Agreement shall be brought only in a court of the State of Michigan or in a court of the United States sitting in Michigan, and both Seller and Buyer submit to and accept generally and unconditionally the personal jurisdiction of those courts. The Agreement sets forth the entire understanding and agreement between the parties with respect to the subject matter hereof and cancels and supersedes all prior agreements, understandings, representations or promises, whether oral or written, between the parties. Nothing herein shall be construed to limit or waive any rights of Seller under applicable Federal, state or local laws.
Having Network Problems?
Take this quiz to get just a glimpse into the health of your network. With a Motivity Technologies network evaluation we can complete a full assessment of your current network and provide recommendations for making your network as healthy as possible.Network Assessment Quiz